Subcontractor Services Agreement (India)

The Subcontractor Services Agreement can be used for a one-time project or for on-going services in India.

File types included

  • Microsoft Word
  • Adobe PDF
  • WordPerfect
  • Rich Text Format

Compatible with

  • Windows
  • Mac OS X
  • Linux

For Immediate Download

Rs.499 INR Add to Cart
60-Day Money Back Guarantee
Please select a state

Lawyer prepared

Our forms are kept up-to-date and accurate by our lawyers

Unlike other sites, every document on FindLegalForms.com is prepared by a lawyer, so you can be sure that you are getting a form that is accurate and valid in India.

Verified in India

Our forms are guaranteed
to be valid in India

Our team works tirelessly to keep our products current. As the laws change in India, so do our forms.

Over 3,500,000
satisfied customers

In over 10 years of creating and selling legal forms, our focus has never changed: providing our customers high quality legal products, low prices and an experience that takes some confusion out of the law.

60-Days Money Back

Try our forms with no risk

If you are unhappy with your form purchase for any reason at all, contact us within 60 days and we will refund 100% of your money back.
A Subcontractor Services Agreement is an agreement between a subcontractor and a general contractor. This type of service agreement is helpful because it provides the terms and conditions of the arrangement. How much will the subcontractor get paid? How long will the subcontractor have to perform its services? What type of work is expected of the subcontractor? These are all questions that will be answered in the agreement. In addition, the agreement will reaffirm that an employer/employee relationship is not created.

The following Subcontractor Services Agreement can be used for a one-time project or for on-going services. In a few cases, you will need to choose the provision that applies to your situation.

Among others, this form includes the following key provisions:
  • Services
  • Time of Completion
  • Equipment
  • Payment
  • Indemnification
  • Arbitration
  • General Provisions
This lawyer-prepared packet contains:
  • Instructions and Checklist for Subcontractor Services Agreement
  • General Information about the Subcontractor Services Agreement
  • Subcontractor Services Agreement for India
Law Compliance:This form complies with the laws of the states and territories of India
Number of Pages7
DimensionsDesigned for Letter Size (8.5" x 11")
EditableYes (.doc, .wpd and .rtf)
UsageUnlimited number of prints
Product number#33573
This is the content of the form and is provided for your convenience. It is not necessarily what the actual form looks like and does not include the information, instructions and other materials that come with the form you would purchase. An actual sample can also be viewed by clicking on the "Sample Form" near the top left of this page.











Subcontractor Services Agreement
(India)








This Packet Includes:
1. Instructions and Checklist
2. General Information
3. Subcontractor Services Agreement







Instructions and Checklist
Subcontractor Services Agreement


   Both the general contractor and subcontractor must sign the Agreement.  Because both parties will want to keep an original copy, two originals should be signed.

   This Agreement should be signed at the beginning of the term of service.

   This Agreement should not be used if the subcontractor is considered an employee of the general contractor.

   You can erase the italicised statements on the Agreement; these are just instructions to help you complete the Agreement.

   Laws vary from time to time. This form is not intended to be and is not a substitute for legal advice. This form should only be a starting point for you and should not be used or signed before first consulting with a lawyer to ensure that it addresses your particular situation. A lawyer should be consulted before negotiating any document with another party.

   The purchase and use of this form is subject to the “Disclaimers and Terms of Use” found at www.findlegalforms.com.





General Information
Subcontractor Services Agreement

A Subcontractor Services Agreement is an agreement between a subcontractor and a general contractor.  This type of service agreement is helpful because it provides the terms and conditions of the arrangement.  How much will the subcontractor get paid?  How long will the subcontractor have to perform its services?  What type of work is expected of the subcontractor?  These are all questions that will be answered in the agreement.  In addition, the agreement will reaffirm that an employer/employee relationship is not created.

The following Subcontractor Services Agreement can be used for a one-time project or for on-going services.  In a few cases, you will need to choose the provision that applies to your situation.

Before you complete and sign your agreement, you should delete the italicised statements on the agreement.  These are just instructions to help you complete the agreement.  You should also delete any optional provisions that you have not chosen to include in your agreement.

Laws vary from time to time, therefore the general contractor and the subcontractor should become familiar with the prevalent laws before entering into this type of arrangement.  In addition, before using the form you should always consult with your lawyer to ensure that it addresses your specific situation.





DISCLAIMER:

FindLegalForms, Inc. (“FLF”) is not a law firm and does not provide legal advice.  The use of these materials is not a substitute for legal advice. Only a lawyer can provide legal advice.  A lawyer should be consulted for all serious legal matters.  No Lawyer-Client relationship is created by use of these materials.  

THESE MATERIALS ARE PROVIDED “AS-IS.  FLF DOES NOT GIVE ANY EXPRESS OR IMPLIED WARRANTIES OF MERCHANTABILITY, SUITABILITY OR COMPLETENESS FOR ANY OF THE MATERIALS FOR YOUR PARTICULAR NEEDS.  THE MATERIALS ARE USED AT YOUR OWN RISK.  IN NO EVENT WILL:  I) FLF, ITS AGENTS, PARTNERS, OR AFFILIATES; OR II) THE PROVIDERS, AUTHORS OR PUBLISHERS OF ITS MATERIALS, BE RESPONSIBLE OR LIABLE FOR ANY DIRECT, INDIRECT, INCIDENTAL, SPECIAL, EXEMPLARY, OR CONSEQUENTIAL DAMAGES (INCLUDING, BUT NOT LIMITED TO, PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES; LOSS OF USE, DATE OR PROFITS; OR BUSINESS INTERRUPTION) HOWEVER USED AND ON ANY THEORY OF LIABILITY, WHETHER IN CONTRACT, STRICT LIABILITY, OR TORT (INCLUDING NEGLIGENCE OR OTHERWISE) ARISING IN ANY WAY OUT OF THE USE OF THESE MATERIALS. 






Subcontractor Services Agreement


This Subcontractor Services Agreement (the “Agreement”) is dated as of               , 20       , by and between                    (“Subcontractor”) and                         __________________ (“General Contractor”) (collectively the “Parties”).

The Parties agree as follows:

1.   SERVICES.  Subcontractor will perform the following services (the “Services”):                                                                                                                                                                                                                                             ________________ .
 
2.   TIME OF COMPLETION.  The Services shall be commenced on or before                 , 20__, and shall be substantially completed by         , 20     .  The Services shall be performed between the hours of        a.m. and        p.m.  Time is of the essence.

3.  EQUIPMENT.  (mark the applicable provision)

   General Contractor shall provide the following equipment for Subcontractors use when performing the Services: _____________________________________________.  Subcontractor will provide all other equipment necessary to perform the Services.

   When performing the Services, Subcontractor will use his/her own equipment.

4.   PAYMENT.  General Contractor shall pay Subcontractor for the material and labour to be performed under this Agreement the total sum of               Rupees.(Rs.                  ).

The payment(s) shall be paid in the following manner:                                                                                                  (Here you will need to describe how the payments will be made.  Will the payments be made in a lump sum at the completion of work?   How much will be paid in advance?  Also include any penalty for failure to complete Services by the stated deadline.)
5.   OTHER EXPENSES.  General Contractor shall reimburse Subcontractor for the following expenses only: ________________________________________________                                          _____________________ (If none, write “none.)


6.   INDEMNIFICATION.  (mark the applicable provision, if any)

   Subcontractor hereby indemnifies and holds harmless General Contractor for any damages, actions, suits, claims or other costs (including reasonable legal and lawyers fees) for which General Contractor may be held liable, arising out of any injury (including death) to any person (including employees of Subcontractor) or damage to any property arising out of the performance of the Work by Subcontractor, or by any employee, service provider, subsidiary, assign, or other affiliate of Subcontractor. (The clause above protects the General Contractor against lawsuits or damages arising out of personal injuries or damage to property caused by Subcontractor.)

   Subcontractor hereby indemnifies and holds harmless General Contractor for any damages, actions, suits, claims or other costs (including reasonable legal & lawyers fees) arising out of Subcontractors performance of the Services pursuant to this Agreement, or arising out of any breach of any of Subcontractors representations or warranties under this Agreement by Subcontractor, or by any employee, subsidiary, service provider, or other affiliate of Subcontractor.(The clause above protects the General Contractor against all damages arising out of Subcontractors performance of its obligations, including any breach of a representation or warranty by Subcontractor, i.e., Subcontractors failure to meet quality standards under Section 8a below.)

7.    ARBITRATION.  Any dispute, claim or controversy arising out of this Agreement or the interpretation, construction, breach or termination of this Agreement, shall be settled by an arbitrator in                (City)        ,    (State)      , according to the provisions of Arbitration & Conciliation Act 1996.  The ruling of the arbitrator shall be final and binding upon the Parties.  Judgment may be entered on any award made by the arbitrator in any court of competent jurisdiction.  The costs of any arbitration pursuant to this Section 7 shall be borne by the Parties equally, except that each Party will be responsible for its own legal fees and expenses.  The arbitrator is empowered, but not required, to apportion the costs of the arbitration (including lawyers fees and expenses) to the Parties as it sees fit.

8.  GENERAL PROVISIONS.

(a)  Subcontractor warrants that all work shall be completed in a workmanship like manner, and if applicable, in compliance with all building codes and other applicable laws.

(b)   Subcontractor warrants that, to the extent required by law, all work shall be performed by individuals duly licensed and authorised by law to perform the work.

(c)   Subcontractor warrants that it is adequately insured for injury to its employees and others incurring loss or injury as a result of the acts of Subcontractor or its employees.

(d)   In the event General Contractor shall fail to pay any periodic or instalment payment due hereunder, Subcontractor may cease work without breach pending payment or resolution of dispute.

(e)  Subcontractor shall not be liable for any delay due to circumstance beyond its control.

(f)  Subcontractor is an independent contractor and not an employee of General Contractor.

(g)   Any changes to this document must be signed by both Subcontractor and General Contractor.
(h)   This Agreement shall be construed in accordance with the laws of the honourable courts of ______________________, India.      
(i)   Neither the General Contractor nor the Subcontractor may assign this Agreement without prior written consent from the non-assigning party.
(j)   The headings of the sections herein are for convenience only, and shall not affect the meaning of the provisions of this Agreement.
(k)   This Agreement constitutes the entire agreement between the General Contractor and the Subcontractor, and supersedes any prior understanding or representation of any kind preceding the date of this Agreement.  There are no other promises, conditions, understandings or other agreements, whether oral or written, relating to the subject matter of this Agreement.


IN WITNESS WHEREOF the Parties have executed this Agreement on the date first written above.


GENERAL CONTRACTOR:         SUBCONTRACTOR:

_______________________________      ______________________________
Signature                        Signature

_______________________________      ______________________________
Name (please print)                  Name (please print)

_______________________________      ______________________________
Title (if applicable)                  Title (if applicable)

_______________________________      ______________________________
Date                           Date


Looking for something else?